3. Rights and obligations of the parties.

3.1. The Contractor undertakes to provide services personally, in full, with proper quality and on time, in accordance with the terms of this Agreement.
3.2. The customer undertakes:
- grant access to the Contractor where to what For example, to the Web site ______________, as well as to provide and (or) approve all materials necessary for the content of the Web site, within 3 days from the date of receipt of an oral or written application from the Contractor.
- assist the Contractor in the performance of work under this Agreement.
- make payment in the prescribed amount and within the established time limits specified in paragraph 2 of this Agreement. 3.3. The contractor has the right to make changes to e.g. website, by prior agreement with the Customer, necessary for the quality provision of services under the Agreement.

4. Terms and conditions for the provision of services (works)

4.1. The provision of services under this Agreement is carried out within amount of days- and banking days after the fulfillment of obligations by the Customer for payment, provided for in clause 2.2. actual agreement.
4.2. Upon the provision of the Services, the Contractor shall submit to the Customer for signing the act of acceptance of the services rendered in two copies.
4.3. During amount of days days after receipt of the acceptance certificate for the services rendered, the Customer is obliged to sign it and send one copy to the Contractor, or, if there are defects, provide the Contractor with a reasoned refusal to sign it.
4.4. If there are deficiencies, the Contractor undertakes to eliminate them within amount of days days from the date of receipt of the relevant claims of the Customer.
4.5. Services are considered rendered from the moment the Parties sign the act of acceptance of the services rendered.

5. Liability of the parties

5.1. For violation of the terms for the provision of the Services, the Customer has the right to demand from the Contractor the payment of a penalty (penalty) in the amount of 0.1% percent of the cost of the Services not rendered on time for each day of delay. 5.1. For violation of the terms for the provision of the Services, the Customer has the right to demand from the Contractor the payment of a penalty (penalty) in the amount of 1% percent of the cost of the Services not rendered on time for each day of delay.

5.2. For violation of the terms of payment, the Contractor has the right to require the Customer to pay a penalty (penalty) in the amount of 0.1% percent of the unpaid amount for each day of delay. 5.2. For violation of the terms of payment, the Contractor has the right to require the Customer to pay a penalty (penalty) in the amount of 1% percent of the unpaid amount for each day of delay.

5.3. In all other cases of non-fulfillment of obligations under the Agreement, the Parties shall be liable in accordance with the current legislation of the Republic of Belarus.

6. Dispute Resolution

6.1. The Parties will strive to resolve all possible disputes and disagreements that may arise under the Agreement or in connection with it, through negotiations.
6.2. Disputes not settled through negotiations are referred to the court in the manner prescribed by the current legislation of the Republic of Belarus.

7. Other terms

7.1. The Agreement may be terminated early by agreement of the Parties or at the request of one of the Parties in the manner and on the grounds provided for by the current legislation of the Republic of Belarus.
7.2. The Agreement is made in two copies, one for each of the Parties.
7.3. This Agreement comes into force from the moment of its signing and is valid until the parties fully fulfill their obligations under this Agreement.

7. Details of the parties

CONTRACTOR CUSTOMER

____________________________ ___________________________________

____________________________ ___________________________________

______________________________ ___________________________________

_____________________________ ___________________________________

_______________ ______________ _________________

Application No. 1

to the contract No. __ dated "__" ________ 201_.

SERVICE LIST

1. Service list

Ready. Download the contract in "DOC" format

Contract for the provision of services. Under a contract for the provision of services for a fee, the contractor undertakes, on the instructions of the customer, to provide services (perform certain actions or carry out certain activities), and the customer undertakes to pay for these services.
The rules of Chapter 39 of the Civil Code apply to contracts for the provision of communication, medical, veterinary, auditing, consulting, information, training, tourism and other services, with the exception of services provided under contracts provided for in Chapters 37, 38, 40, 41, 44, 45, 46, 47, 49, 51, 53 of the Civil Code.

Unless otherwise provided by the contract for the provision of services for compensation, the contractor is obliged to provide services personally.

The customer is obliged to pay for the services rendered to him in the terms and in the manner specified in the contract for the provision of services for compensation.

In case of impossibility of performance due to the fault of the customer, the services are subject to payment in full, unless otherwise provided by law or the contract for the provision of services for compensation.

In the event that the impossibility of performance has arisen due to circumstances for which none of the parties is responsible, the customer shall reimburse the contractor for the expenses actually incurred by him, unless otherwise provided by law or the contract for the provision of services for compensation.

The customer has the right to refuse to execute the contract for the provision of services for compensation, subject to payment to the contractor of the expenses actually incurred by him.

The contractor has the right to refuse to fulfill obligations under the contract for the provision of services for compensation only if the customer is fully reimbursed for losses.

The general provisions on the contract (Articles 702-729 of the Civil Code) and the provisions on domestic contracting (Articles 730-739 of the Civil Code) apply to the contract for the provision of services for compensation, unless this contradicts Articles 779-782 of the Civil Code, as well as the specifics of the subject matter of the contract for the provision of services for compensation.

Phantom Limited Liability Company, hereinafter referred to as the “Customer”, represented by Director Nikolay Aleksandrovich Verevkin, acting on the basis of the Charter, on the one hand, and Individual Entrepreneur Fedichkin A.V., hereinafter referred to as the “Executor”, represented by Andrey Vladimirovich Fedichkin , acting on the basis of the Certificate, on the other hand, hereinafter collectively referred to as the "Parties", have concluded this agreement as follows:

1. THE SUBJECT OF THE AGREEMENT

1.1. The Contractor undertakes on its own to provide services for participation in the production process, management and performance of other functions at the request of the Customer, on the territory of the Customer's enterprise, located at: Moscow, st. Olkhovskaya, 11.
1.2. The Customer undertakes to timely pay for the services to the Contractor.

2. RIGHTS AND OBLIGATIONS OF THE PARTIES

2.1. The performer has the right:
2.1.1. Get access to the internal local acts of the Customer, technical documentation, as well as other sources of information regarding the security of the object.
2.1.2. Has the right to change the cost of the services provided, but not more than once during the calendar year.
2.2. The Contractor undertakes:
2.2.1. Within the agreed timeframe, fulfill the Customer's instructions provided for in this Agreement.
2.2.2. At the written request of the Customer, conduct a survey of the facilities, followed by drawing up an act that reflects proposals for technical reinforcement, the use of technical means, the type, the required number of posts and the number of guards at the facility.
2.2.3. Carry out, at the written request of the Customer, consulting and preparing recommendations on the issues of ensuring the security of the Customer's facilities.
2.2.4. Provide assistance in maintaining fire safety in the premises, subject to the Customer's implementation of fire prevention measures and provision of primary fire extinguishing equipment.
2.2.6. Activities specified in paragraphs 2.2.2; 2.2.3., carry out for an additional fee.
2.3. The customer has the right:
2.3.1. Make suggestions to improve the quality of services provided by the Contractor.
equipment necessary for the Contractor to fulfill its obligations.
2.4.3. Install serviceable primary fire extinguishing equipment in certain places at the facility, carry out preventive fire safety measures.
2.4.4. Provide lighting for the facility.
2.4.5. Require from their employees, as well as from customers, visitors and partners, to comply with fire safety measures on the territory of the enterprise.
2.4.6. Timely pay for the services of the Contractor under this agreement.
2.4.7. Notify the Contractor in writing within 2 (Two) business days of the change of the head, as well as other persons responsible for contractual relations, with confirmation of their authority (orders, powers of attorney, instructions), change of company details with sending documents confirming these changes to Contractor's address.

3. COST OF SERVICES AND PAYMENT PROCEDURE

3.1. The cost of the Contractor's services under this Agreement is 103,960 (One hundred and three thousand nine hundred and sixty) rubles 00 kopecks per month.
3.2. Payment for the Contractor's services is made by transferring funds to the Contractor's settlement account in the following order:
- advance payment (prepayment) of at least 60% of the amount of payment for the Contractor's services for the previous month before the 05th day of the current month on the basis of an invoice,
- final settlement - before the 10th day of the month following the reporting one.
3.3 The Customer is obliged to review the submitted act within 3 working days, sign it, certify it with a seal, and return one copy to the Contractor's address. If there are comments on the services rendered, the Customer returns the act with a reasoned refusal in writing within the period specified above. If the act is not received by the Contractor within the agreed period, the services are considered accepted by the Customer under the act without comment.
3.4. If the conditions that determine the cost of services change, the Contractor shall notify the Customer in writing, 10 days in advance and provide a new calculation for consideration by the Customer.
An agreement on changing the cost of services is executed by signing an additional agreement to the Agreement by the Parties to the Agreement without reissuing the Agreement.
3.5. In case of non-receipt of funds to the Contractor's settlement account within the time limits specified in clause 3.2. of this Agreement, the Contractor has the right to unilaterally suspend this Agreement by notifying the Customer in writing 1 day before the proposed suspension of the provision of services.
3.6. In case of non-payment of the debt on payment for the services of the Contractor within one month from the date of suspension of this Agreement, the Contractor has the right to unilaterally terminate the Agreement without additional notice to the Customer.
3.7. The date of fulfillment by the Customer of its obligations to pay for the services of the Contractor is the day of receipt of funds to the settlement account of the latter.

4. RESPONSIBILITIES OF THE PARTIES

4.1. For non-fulfillment or improper fulfillment of obligations under this agreement, the parties are liable in accordance with the current legislation of the Russian Federation.
4.2. For each day of delay in payment for the provision of personnel with ^ U, a penalty in the amount of 0.1% of the amount owed. The penalty is charged on the basis of sending a written claim by the Contractor to the Customer and a written confirmation of the Customer on its acceptance. The penalty is charged from the date of written confirmation of acceptance of the claim by the Customer.
4.3 The Contractor in case of improper performance or non-performance of the terms of this agreement is liable for damage caused to the Customer.
4.4. The facts of causing damage are established by the bodies of inquiry, the investigation, the court in the manner prescribed by applicable law.
The guilt of the Contractor is established by a bilateral commission consisting of representatives of the Customer and the Contractor, in case of disputes over the guilt of the Contractor that cannot be resolved by the specified commission, the dispute is referred to the court.
The amount of damage is confirmed by the relevant documents drawn up with the participation of the Contractor. In the event of a discrepancy between the amount of damage established by the Customer and the amount of damage established by the court, the damage established by the court shall be subject to compensation.
Compensation for damage is made after the drawing up of a bilateral act, or a verdict, decision, ruling or court order that has entered into legal force.
4.5. The amount of damage not disputed by the parties shall be reimbursed within 30 days after the Customer provides the Contractor with a complete package of required documents.
4.6. The Contractor is released from liability:
- for damage caused through the fault of the Customer's employees during the performance of their labor duties;
— for the theft of personal property of the Customer's employees;
- for theft from sealed, sealed or locked premises without breaking seals, seals, doors and locks and other obvious signs of penetration into the Customer's premises;
- for damage caused by fire, explosion, riots, other natural disasters.

5. ACTIONS OF FORCE MAJEURE

5.1. The parties are released from liability for partial or complete failure to fulfill obligations under this agreement, if this failure was the result of force majeure circumstances that arose after the conclusion of the agreement as a result of extraordinary events, the occurrence of which the party that did not fulfill the obligations in full or in part could neither foresee nor prevent by reasonable means.
In this case, the fulfillment of obligations under the contract is postponed for the duration of the force majeure circumstances.
5.2. Upon the occurrence of those specified in clause 5.1. circumstances, the party for which it became impossible to fulfill its obligations under this agreement must, as soon as possible, notify the other party in writing about them, attaching the relevant certificates, but in any case no later than 10 days after their commencement.

6. PRIVACY

6.1. The terms of this agreement and agreements (protocols, etc.) to it are confidential and not subject to disclosure.
6.2. The Parties take all necessary measures to ensure that their employees, without the prior consent of the other Party, do not inform third parties about the details of this agreement and its annexes.

7. TERM AND OTHER CONDITIONS OF THE AGREEMENT

7.1. This Agreement shall enter into force from 09.00 am "01" June 20__. and is valid for 1 (one) year.
7.2. The terms of the agreement and its appendices may be changed by agreement of the parties. Changes and additions are considered within two weeks.
7.3. The cost of providing services under this agreement is subject to annual indexation, taking into account the growth rate of inflation in the territory of the Russian Federation.
7.3. Each of the parties has the right to terminate this Agreement at any time and sends a written notice of termination of the agreement to the other party about its intention 30 (thirty) days in advance. During this period, the parties shall fulfill their obligations under this Agreement.
7.4. If 15 days before the expiration of this Agreement, the parties have not notified in writing of the termination of this Agreement, then it is considered extended for each subsequent calendar year on the same terms. In the manner prescribed by this paragraph, this Agreement may be extended an unlimited number of times.
7.5. All disputes of the parties under this agreement and in connection with it, on which the parties cannot reach a mutual agreement, are resolved in the Arbitration Court of the Moscow Region.
7.6. This Agreement is made in two copies, each of which has equal legal force, one for each of the parties.

8. LEGAL ADDRESSES AND DETAILS OF THE PARTIES
________________________
________________________

Relations under the contract for the provision of services have been known to civil law for thousands of years. However, with rare exceptions, there were no special rules in the codified acts on the regulation of these relations.

Types of service contracts

Often, only the types of contracts for the provision of services (or obligations) were regulated in legislation. This led to the high prevalence in legal practice and the Internet of samples of a contract for the provision of services with varying degrees of legal elaboration and stipulated conditions.

Obligations in 2019 under a service agreement can develop in various areas of human activity, which means that there are a huge number of types of service agreements: security, consulting, information services, and much more. Their range is constantly expanding, so it is impossible to compile an exhaustive list of areas described by contracts for the provision of services.

Currently, obligations to provide services, drawn up in the form of a contract, are the newest institution for Russian legislation, although some of their types have been met before. The provision of services can be both paid and free of charge. In the latter case, the parties rarely resort to concluding a written agreement. A legally competent form of a contract for the provision of services has been developed by our team of experts in full compliance with the current Civil Code of the Russian Federation. The paid services agreement protects both parties, both the contractor in his obligations to provide services (perform certain actions or carry out certain activities), and the customer (to accept these services and pay for them). The term of the contract in most cases corresponds to the term of the service. At the same time, it is important to remember the differences between the contract for the provision of services and contracts for work, transportation, commissions, instructions in order to put into practice a document that most fully meets the requirements and expectations of the parties.

Recall that the contract for the provision of paid services must necessarily list all the services provided by the contractor, the task of the customer and the procedure for settlements between the parties.

Samples of related documents, which include the form of the contract for the provision of services for a fee, are the act (delivery and acceptance of services), reports of the contractor (including the costs associated with the provision of services), additional agreements to the contract, protocols of disagreements, as well as protocols for their coordination .

There are no significant differences between the samples of contracts for the provision of services for a fee by individuals and legal entities.

The standard form of the contract for the provision of services has the following features:

• The subject of the contract is a rather specific object - services.
• Personal performance is of the utmost importance for the customer. Those. he is interested in the services, the description of which contains a sample contract for the provision of services, to be performed by a specific contractor.
• The requirement for licensing certain types of activities (providing medical services, an auditor or a lawyer, communication services, veterinary, etc.).

The service obligation is a legal relationship by virtue of which the contractor (service provider) undertakes to provide the customer (service guarantor) with a certain intangible (non-objective) benefit (benefit), and the customer undertakes to pay the contractor for his actions or activities containing this benefit. (Sample contract for the provision of services for a fee, as well as other contracts for the provision of services for a fee at the end of the page).

Similar articles:

Under a contract for the provision of services for a fee, the contractor undertakes, on the instructions of the customer, to provide services (perform certain actions or carry out certain activities), and the customer undertakes to pay for these services ( paragraph 1 of Art. 779 Civil Code of the Russian Federation).

From the definition, the following conclusions can be drawn regarding the concept of the named contract. *

Firstly, this agreement is consensual.

Secondly, since under the contract for the provision of services for a fee, both the contractor (service provider) and the customer (service recipient) acquire subjective rights and assume subjective obligations, then this contract is bilaterally binding (mutual).

Third, this contract is linear, i.e. the fulfillment of the obligation to provide services for a fee is carried out by the parties personally, unless otherwise provided by the contract ( Art. 780 Civil Code of the Russian Federation). But this agreement can also be constructive, i.e. the fulfillment of an obligation may be assigned to a third party or an agreement may be concluded in favor of a third party (this is especially common in tourist services, and in other obligations where the service, by its economic nature, can only be provided to individuals).

Fourth, this contract is paid (the price is a usual condition of the contract), i.e. norms ch. 39 The Civil Code of the Russian Federation regulates relations exclusively for the provision of paid services. Some authors, recognizing the existence of a gratuitous contract for the provision of services, conclude that this contract does not give rise to an obligation to provide services.**

CONTRACTPAYABLE PROVISION OF SERVICES

Hereinafter referred to as ___ "Customer", represented by __________, acting ___ on the basis of ____________, on the one hand, and ______________, hereinafter referred to as __ "Contractor", represented by ____________, acting ___ on the basis of ________, on the other hand, collectively referred to as the "Parties", and individually, the “Party”, have entered into this agreement (hereinafter referred to as the Agreement) as follows.

SUBJECT OF THE CONTRACT

1.1. The Contractor undertakes to provide the Customer with the services listed in Appendix No. 1 to the Agreement “List of Services Provided” (hereinafter referred to as the Services), and the Customer undertakes to pay for these Services.

1.2. Executor (choose one)

• undertakes to provide the Services personally.
• has the right to involve third parties in the provision of the Services without the prior consent of the Customer.

1.3. Timing provision of the Services are defined in the List of Services Provided (Appendix No. 1).

1.4. Services are provided ________________________ (location of the Party or facility in respect of which services are provided, other).

PROCEDURE OF PROVISION OF SERVICES

2.1. The quality of services and their results must meet the following mandatory requirements: ______________________________________.

2.2. At the request of the Contractor sent by e-mail for information, documents, additional materials and (or) equipment Customer no later than ___ (_______) working days from the date of delivery of the message gives appropriate explanations, information, documents, materials and (or) equipment in the form specified by the Contractor in the request.

2.3. If the Customer provides documents, materials and (or) equipment The contractor is obliged to ensure their safety. The Contractor returns to the Customer the remaining materials and (or) equipment, taking into account normal wear and tear, with the Acceptance and Delivery Certificate for the Services Rendered or with the unilateral Acceptance and Delivery Certificate for the Services Rendered.

2.4. The Customer has the right to check the progress of the provision of services under the Agreement. For these purposes, the Customer:

• requests relevant information orally or in writing, including by sending a message to the Contractor by e-mail. The Contractor, no later than __ (__________) working days, provides the Customer in oral or written form with a report on the progress of the provision of services;
• exercises control for the provision of services. The Contractor is obliged to provide appropriate access to the Customer and not interfere with the control.

PROCEDURE FOR DELIVERY AND ACCEPTANCE OF SERVICES

3.1. Upon the provision of the Services, the Contractor shall submit to the Customer for signing the Certificate of Acceptance and Delivery of the Services Rendered in two copies in the form agreed in Appendix No. 2.

3.2. Services are considered rendered from the moment the Parties sign the Certificate of Acceptance and Delivery of Services Rendered.

3.3. The act of rendering services is drawn up in accordance with the requirements of Art. 9Federal Law of 06.12.2011 N 402-FZ "On Accounting" to the execution of primary accounting documents.

3.4. Acceptance certificate services rendered The performer makes and signs in two copies and sends it to the Customer for signing no later than ______ (______) working days from the end of the term for the provision of services.

3.5. Within _____ (________) working days after receipt of the Certificate of acceptance and delivery of services rendered The customer must sign it and send one copy to the Contractor or, if there are deficiencies in the quality of the services provided and (or) as a result, provide the Contractor with a reasoned refusal to sign it.

3.6.In case of deficiencies as the services provided and (or) as a result of them Customer according to Art. 723 of the Civil Code of the Russian Federation entitled (choose one)

• demand gratuitous eliminate The Contractor of such shortcomings within ______ (______) working days from the date of receipt of the relevant requirement of the Customer.
• demand proportionate decrease the cost of the Contractor's services.
• eliminate deficiencies on your own or by third parties and require the Contractor to reimburse the costs of elimination.

3.7.After correcting deficiencies The Contractor draws up a repeated Acceptance and Delivery Certificate for the services rendered, which is subject to review, signing and sending by the Customer in the prescribed manner.

3.8. In case of evasion or unmotivated refusal of the Customer from signing the Certificate of acceptance and delivery of services rendered, the Contractor, after _______ (________) working days from the end of the last day of the period established for consideration, signing and sending this document, has the right to draw up a unilateral Certificate of acceptance and delivery of services rendered.

The Contractor, no later than ____ (__________) business days from the date of drawing up a unilateral Acceptance Certificate for the services rendered, is obliged to send a copy of it to the Customer.

PRICE AND PAYMENT PROCEDURE

4.1. The total cost of the Services is _____ (__________) rubles, including VAT _____ (__________) rubles.

4.2. The Customer pays for the Services in the following order (select the one you need / it is possible to establish a different payment procedure)

• before the beginning provision of Services by the Contractor (advance payment).
• during _____ (__________) working days after the signing by the Parties of the Acceptance and Delivery Certificate for the Services rendered or from the moment of drawing up a unilateral Acceptance and Delivery Certificate for the Services rendered in cases stipulated by the Agreement.
• part of the cost of the Services in the amount _____ (__________) rubles, including VAT _____ (__________) rubles, the Customer pays before the start of the provision of services by the Contractor (prepayment), the remaining part of the cost of the Services in the amount of _____ (__________) rubles, including VAT _____ (__________ ) rub., the Customer pays within _____ days after the Parties sign the Acceptance and Delivery Certificate for the Services rendered or from the moment the unilateral Acceptance and Delivery Certificate for the Services rendered is drawn up in cases stipulated by the Agreement.

4.3. Interest on the amount of payment under the Agreement are not accrued and are not paid.

4.4. All calculations under contract produced in cash by transferring funds to the settlement account of the Contractor specified in the Agreement. The Customer's payment obligations are considered to be fulfilled on the date the funds are credited to the correspondent account of the Contractor's bank.

RESPONSIBILITIES OF THE PARTIES

5.1. Behind violation of deadlines provision of Services(clause 1.3 of the Agreement) the Customer has the right to require the Contractor to pay a penalty (penalties) in the amount of _____ (__________) percent of the cost of Services not rendered on time for each day of delay.

5.2. Behind violation of payment deadlines(Clause 4.2 of the Agreement) The Contractor has the right to require the Customer to pay a penalty (penalties) in the amount of _____ (__________) percent of the unpaid amount for each day of delay.

5.3.Party that did not comply or improperly performed the obligations under the Agreement, obligated to reimburse the other Party damages caused by such violations.

5.4. In all other cases of non-fulfillment of obligations under the Agreement, the Parties shall be liable in accordance with the legislation of the Russian Federation.

FORCE MAJEURE (force majeure)

6.1. The parties are released from liability for non-fulfillment or improper fulfillment of obligations under the Agreement, if proper fulfillment turned out to be impossible due to force majeure, that is, extraordinary and unavoidable circumstances under the given conditions, which are understood as: _____________________________ (prohibited actions of the authorities, civil unrest, epidemics, blockades, embargoes, earthquakes, floods, fires or other natural disasters).

6.2. In the event of these circumstances Party is obliged within _____ (__________) working days notify about it to the other Party.

6.3. Document issued by _________________________ (authorized state body, etc.), is sufficient evidence of the existence and duration of force majeure.

6.4. If force majeure circumstances continue to operate for more than _____, then each Party has the right to withdraw from the Agreement unilaterally.

TERM, AMENDMENT AND EARLY TERMINATION OF THE AGREEMENT

7.1. The contract is valid for _____ from the date of its conclusion.

7.2. All changes and additions to the Agreement are valid if made in writing and signed by both Parties. The relevant additional agreements of the Parties are an integral part of the Agreement.

7.3. The Agreement may be terminated early by agreement of the Parties., or at the request of one of the Parties in the manner and on the grounds provided for by the legislation of the Russian Federation.

DISPUTES RESOLUTION

8.1. All disputes related to the conclusion, interpretation, execution and termination of the Agreement, will be resolved by the Parties through negotiations.

8.2. In case of failure to reach an agreement during the negotiations, the interested Party sends a claim in writing, signed by an authorized person.

Claims can be submitted in any of the following ways:

• by registered mail with acknowledgment of receipt;
• courier delivery. In this case, the fact of receipt of the claim must be confirmed by a receipt, which must contain the name of the document and the date of its receipt, as well as the surname, initials, position and signature of the person who received this document.

Claim entails civil law consequences for the Party to which it was sent, from the moment of its delivery to the specified Party or its representative. Such consequences also arise in the case when the claim was not delivered to the addressee due to circumstances depending on him.

The claim is considered delivered if it:

• received by the addressee, but due to circumstances depending on him, was not delivered or the addressee did not familiarize himself with it;
• delivered to the address indicated in the Unified State Register of Legal Entities or named by the addressee himself, even if the latter is not located at such an address.

8.3. Documents must be attached to the claim. substantiating the claims made by the interested Party (if the other Party does not have them), and documents confirming the authority of the person who signed the claim. These documents are submitted in the form of duly certified copies. If the claim is submitted without documents confirming the authority of the person who signed it, then it is considered unreported and is not subject to review.

8.4. Side to which the claim is directed, obliged to consider the received claim and notify the interested Party in writing of the results within ___ (_____) working days from the date of receipt of the claim.

8.5.In case of non-resolved disputes in the claim procedure, as well as in case of non-receipt of a response to the claim within the period specified in clause 8.4 of the Agreement, the dispute is referred to arbitration at the location of the defendant in accordance with the legislation of the Russian Federation.

FINAL PROVISIONS

9.1. Agreement enters into force from the moment of its signing by the Parties.

9.2. Unless otherwise provided by the Agreement, notices and other legally significant notices may be sent by the Parties by fax, e-mail or by any other method of communication, provided that it allows to reliably establish from whom the message originated and to whom it is addressed.

9.3. The contract is made in two copies, one for each of the Parties.

9.4. Attached to the Agreement:

• List of rendered services (Appendix N 1);
• The act of acceptance and delivery of services rendered (Appendix N 2);
• ________________________________.